TERMS AND CONDITIONS
CEO Enterprises
Effective Date: December 2025

1. INTRODUCTION

These Terms govern access to and use of www.ceoenterprises.in and all services and transactions of CEO Enterprises (“Company”).
Use of the website or engagement in any transaction constitutes acceptance of these Terms.

2. NATURE OF BUSINESS

CEO Enterprises provides electrical contracting, project execution, consulting, and related solutions.
Website content is indicative only and does not constitute a binding offer.
Binding agreement arises only through quotation, work order, or written contract.

3. SCOPE OF SERVICES

All service details are indicative. Final scope, timelines, and deliverables shall be governed by approved documents.
Any variation requires written approval and may affect cost and timelines. No work beyond agreed scope shall be executed without approval.

4. PRICING AND COMMERCIAL TERMS

All pricing is indicative and subject to site conditions, materials, and project requirements.
Final pricing shall be as per official quotation. Company reserves the right to revise pricing prior to agreement.

5. BILLING AND PROOF OF PURCHASE

A valid invoice is mandatory for all claims including warranty, service, returns, and disputes.
Claims without invoice may be denied.

6. PAYMENT TERMS

Payments shall be as per agreed terms. Delay may result in suspension of work, withholding of delivery, and additional charges.
The Company reserves the right to charge interest on delayed payments and recover collection costs.

7. PROJECT EXECUTION AND DELAYS

Project timelines are estimates and depend on site readiness, approvals, material availability, and external factors.
The Company shall not be liable for delays caused by client-side issues, approval delays, or third-party dependencies.
Client-caused delays may result in additional cost, idle charges, or timeline revision.

8. MATERIALS, OWNERSHIP, AND RISK

Ownership of goods shall remain with the Company until full payment is received.
Risk in goods transfers to the customer upon delivery or handover.
The Company is not responsible for pre-existing site conditions, third-party work, or improper usage after handover.

9. WARRANTY LIMITATION

Warranty is limited to manufacturer terms or written agreement.
Warranty excludes misuse, unauthorized modification, and external damage.

10. INSPECTION AND ACCEPTANCE

The customer shall inspect goods or services within 7 days of delivery or completion.
Failure to raise written objections within this period shall constitute deemed acceptance.

11. STORAGE, COLLECTION, AND ABANDONED GOODS

Customer shall collect goods within 7 days of intimation.
After 7 days, goods shall be held at customer’s risk and storage charges may apply.
After 20 days, the Company may dispose or liquidate goods and recover dues without liability.
No claims shall arise post-disposal.

12. LIMITATION OF LIABILITY

The Company shall not be liable for indirect, incidental, or consequential losses.
Total liability, if any, shall not exceed the value of the relevant invoice.

13. INDEMNIFICATION

Customer agrees to indemnify the Company against claims arising from misuse, breach, or unlawful actions.

14. FORCE MAJEURE

The Company shall not be liable for delays or failure due to events beyond reasonable control.

15. TERMINATION

The Company may suspend or terminate services in case of non-payment, breach, or unsafe conditions.
All dues remain payable upon termination.

16. CLAIM LIMITATION

Any claim must be raised within 7 days from delivery or completion, failing which it shall be deemed waived.

17. COMMUNICATION

Communication via call, SMS, email, or messaging platforms shall be considered valid and binding.

18. SUBCONTRACTING

The Company reserves the right to engage third-party vendors or subcontractors for execution of work.

19. SAFETY AND SITE RESPONSIBILITY

The customer shall ensure safe and compliant site conditions.
The Company shall not be liable for risks arising from unsafe or non-compliant environments.

20. ENTIRE AGREEMENT

These Terms, along with quotation and related documents, constitute the entire agreement between the parties.

21. DOCUMENT PRIORITY

In case of any conflict between these Terms and any quotation, work order, or agreement, the terms specified in the quotation or signed agreement shall prevail.

22. SEVERABILITY

If any provision is held invalid, the remaining provisions shall remain enforceable.

23. GOVERNING LAW AND JURISDICTION

These Terms shall be governed by the laws of India.
Jurisdiction: Maharashtra courts.

24. DISPUTE RESOLUTION (NEW)

Parties shall first attempt to resolve disputes through mutual discussion.
If unresolved, disputes may be referred to mediation or arbitration before initiating legal proceedings.

25. REFUND AND CANCELLATION (NEW)

Payments once made are non-refundable unless explicitly agreed in writing.
Cancellation of orders or services may be subject to applicable charges, including work completed, materials procured, and administrative costs.

26. MODIFICATIONS

The Company reserves the right to update these Terms at any time. Continued engagement constitutes acceptance.

27. ACCEPTANCE OF TERMS

By engaging in any transaction with the Company, including purchase, service, payment, or delivery, the customer agrees to these Terms.
Acceptance applies across all channels and does not require physical signature.

28. CONTACT INFORMATION

CEO Enterprises
Website: www.ceoenterprises.in

Terms & Conditions